Tolibas Construction v. Wang
Defendants Gary Wang and Jill Pope Wang, individually and as trustees of the Wang Family Revocable Trust (collectively, the Wangs), appeal from a judgment following a court trial in favor of plaintiff Tolibas Construction, Inc., a California corporation, doing business as T & G Construction (Tolibas), in Tolibass action for breach of a construction contract and the Wangs cross-action for breach of contract and fraud. The Wangs contend the court erred in failing to award them damages due to Tolibass delay and other breaches of the parties construction contract, and erred in awarding Tolibas a 15 percent final payment fee and prejudgment interest. Tolibas cross-appeals from the judgment on the ground that the damages offset awarded to the Wangs was improperly calculated.
Comments on Tolibas Construction v. Wang